How about best practice for documenting delays in the schedule as activities and or notbook entries. Is there are accepted best practace / documents on this.
It is noteworthy that the need for analysts to take resource allocations into account in their delay analyses is becoming an increasingly vital requirement. For instance, in the UK case of McAlpine Humberoak vrs McDermott International [29], the judge disapproved of the plaintiff’s delay claim submissions on the basis of not giving consideration on how resource usage was planned for and how they were actually utilized during construction. Wickwire [43] also reviewed legal decisions in the US and noted that “in any analysis of project delays, the contractor is required to take into account realistic resource leveling”.
Member for
7 years 10 monthsHow about best practice for
How about best practice for documenting delays in the schedule as activities and or notbook entries. Is there are accepted best practace / documents on this.
Member for
7 years 10 monthsHow about the documentation
How about the documentation of the delay in the schedule as it occurs - delay activities. Is there a recomended practice for this?
Member for
5 years 3 monthslook at this
look at this presentation
https://www.linkedin.com/posts/%D8%B9%D9%84%D9%85-%D9%8A%D9%86%D8%AA%D9…
Member for
16 years 3 monthslook at AACE Best Practice No
look at AACE Best Practice No 29R-02 Forenesic Analsis
and
AACE Best Practice Time Impact Analysis 52R-06
Member for
21 years 8 monthsConstruction Delay Analysis
Construction Delay Analysis Techniques—A Review of Application Issues and Improvement Needs
It is noteworthy that the need for analysts to take resource allocations into account in their delay analyses is becoming an increasingly vital requirement. For instance, in the UK case of McAlpine Humberoak vrs McDermott International [29], the judge disapproved of the plaintiff’s delay claim submissions on the basis of not giving consideration on how resource usage was planned for and how they were actually utilized during construction. Wickwire [43] also reviewed legal decisions in the US and noted that “in any analysis of project delays, the contractor is required to take into account realistic resource leveling”.
Schedule Analysis under the Effect of Resource Allocation (PDF)
Schedule Float Game ENR