A copy of Rafael Davila's reply should be framed and hung in every project office, and taught in every planning AND contracts course!
Personally, I learned the term Ghost Schedule! And I love it!
As a West Indian, I'd also like to nominate a new term: Zombie Schedule. It's one that is so outdated as to be dead -- yet some on the project are still trying to use it! This is very common with US aerospace/DoD contractors.
Fraternally in project management,
Steve the Bajan
Member for
20 years 6 months
Member for20 years7 months
Submitted by Zhang Haixiang on Wed, 2019-08-14 08:38
1) The Contract schedule that more often than not cannot be used for management at the site as the Contract Schedule is frequently lagging revised logic and activities necessary to manage the project. In most of our jobs the client never approve revisions to the contract schedule on time for it to be useful for site management while the project finishes with no court claim.
2) An Optimistic schedule that is based on aggressive estimates of project parameters we use for project management. It will include those activities not yet in contract schedule but that are required to manage the schedule no matter if approved or not. It will not include allowance for rain days as it is not a good idea to plan short term activities assuming it will rain before it happens. It will not include contingencies as it is not a good idea to include them within this schedule because of Student Syndrome and Parkinson's Law. The Student Syndrome is tolerable for a few, non-critical tasks. But when the number of critical tasks affected increases, then whole schedule will be at risk. Parkinson's Law is the adage that "work expands so as to fill the time available for its completion".
It is necessary to target for some early completion in order to increase the probabilities of meeting contractual requirements, otherwise you will be targeting for failure. The period between planned completion and completion date or Terminal Float is owned by the contractor under the contract and is mandated in some European contract models such as the NEC to the point if there is no terminal float shown the schedule might be rejected.
USA practice is the opposite, terminal float is usually prohibited and interpreted as a reduction in contract time; therefore we have no other option than to make use of Ghost Schedules if we want to increase the probabilities of meeting contract dates. This schedule does not needs to be shown to the client [1]. This schedule will include contract schedule activities plus a few additional not yet included, in this way we keep actuals of these activities that while not in the contract schedule are actually happening. We use this version as the basis for updating the Contract Schedule as it will include all activities within both versions and synchronize updating using Spider Project capabilities for doing so.
[1] Ghost Schedule- In a significant case concerning Ghost Schedules and their use, Jackson Construction, Inc. v. United States.7 the U.S. Court of Federal Claims stated that a contractor is under no obligation to advice owners of its planned early completion [Ghost Schedule].
Member for
24 years 9 months
Member for24 years9 months
Submitted by Vladimir Liberzon on Mon, 2019-08-12 11:06
it is usual and recommeneded practice for Spider Project users to create and to maintain three project schedules:
1) Contract schedule that may be considered as pessimistic. This schedule includes required contingency reserves and cost estimates are contractual.
2) Project Control (expected) schedule based on expected estimates of activity durations, costs (expenses) and resource availability.
3) Optimistic schedule that is based on aggressive estimates of project parameters.
Optimistic schedule is used for project workforce management.
In Spider Project these three schedules can be linked so that when you enter actual information in any of them all three will be updated automatically. So the need to duplicate work does not exist.
Besides, Spider Project calculates probabilities to meet target parameters with any update that is very helpful for project management.
Sometimes, other than the schedule submitted to Client, an internal schedule will be developed by the Contractors. It is tracking schedule, ghost schedule etc. Main pupose of internal schedule is to execute the works in the best possible ways incorporating all potential risk factors-both threats & oppurtunities. Also will be helpful to control the activities of sub-contractors using this internal schedule. Contractor will try to finish all the works ahead of schedule submitted to client, by closely monitoring the internal schedule with all best efforts.
BR
Kannan
Member for
16 years 3 months
Member for16 years4 months
Submitted by Zoltan Palffy on Thu, 2019-08-08 12:36
Member for
21 years 8 months(No subject)
Member for
20 years 7 monthsRafael, good. We're even!
Rafael, good. We're even!
Member for
21 years 8 monthsSteve:Zombie Schedule: It's
Steve:
Zombie Schedule: It's one that is so outdated as to be dead.
Best Regards,
Rafael
Member for
20 years 7 monthsA copy of Rafael Davila's
A copy of Rafael Davila's reply should be framed and hung in every project office, and taught in every planning AND contracts course!
Personally, I learned the term Ghost Schedule! And I love it!
As a West Indian, I'd also like to nominate a new term: Zombie Schedule. It's one that is so outdated as to be dead -- yet some on the project are still trying to use it! This is very common with US aerospace/DoD contractors.
Fraternally in project management,
Steve the Bajan
Member for
20 years 6 monthsThanks for your reply.
Thanks for your reply.
Member for
21 years 8 monthsMy approach is to keep two
My approach is to keep two versions:
1) The Contract schedule that more often than not cannot be used for management at the site as the Contract Schedule is frequently lagging revised logic and activities necessary to manage the project. In most of our jobs the client never approve revisions to the contract schedule on time for it to be useful for site management while the project finishes with no court claim.
2) An Optimistic schedule that is based on aggressive estimates of project parameters we use for project management. It will include those activities not yet in contract schedule but that are required to manage the schedule no matter if approved or not. It will not include allowance for rain days as it is not a good idea to plan short term activities assuming it will rain before it happens. It will not include contingencies as it is not a good idea to include them within this schedule because of Student Syndrome and Parkinson's Law. The Student Syndrome is tolerable for a few, non-critical tasks. But when the number of critical tasks affected increases, then whole schedule will be at risk. Parkinson's Law is the adage that "work expands so as to fill the time available for its completion".
It is necessary to target for some early completion in order to increase the probabilities of meeting contractual requirements, otherwise you will be targeting for failure. The period between planned completion and completion date or Terminal Float is owned by the contractor under the contract and is mandated in some European contract models such as the NEC to the point if there is no terminal float shown the schedule might be rejected.
USA practice is the opposite, terminal float is usually prohibited and interpreted as a reduction in contract time; therefore we have no other option than to make use of Ghost Schedules if we want to increase the probabilities of meeting contract dates. This schedule does not needs to be shown to the client [1]. This schedule will include contract schedule activities plus a few additional not yet included, in this way we keep actuals of these activities that while not in the contract schedule are actually happening. We use this version as the basis for updating the Contract Schedule as it will include all activities within both versions and synchronize updating using Spider Project capabilities for doing so.
[1] Ghost Schedule- In a significant case concerning Ghost Schedules and their use, Jackson Construction, Inc. v. United States.7 the U.S. Court of Federal Claims stated that a contractor is under no obligation to advice owners of its planned early completion [Ghost Schedule].
Member for
24 years 9 monthsHi Zhang,it is usual and
Hi Zhang,
it is usual and recommeneded practice for Spider Project users to create and to maintain three project schedules:
1) Contract schedule that may be considered as pessimistic. This schedule includes required contingency reserves and cost estimates are contractual.
2) Project Control (expected) schedule based on expected estimates of activity durations, costs (expenses) and resource availability.
3) Optimistic schedule that is based on aggressive estimates of project parameters.
Optimistic schedule is used for project workforce management.
In Spider Project these three schedules can be linked so that when you enter actual information in any of them all three will be updated automatically. So the need to duplicate work does not exist.
Besides, Spider Project calculates probabilities to meet target parameters with any update that is very helpful for project management.
Member for
17 years 5 monthsHi Zhang,Sometimes, other
Hi Zhang,
Sometimes, other than the schedule submitted to Client, an internal schedule will be developed by the Contractors. It is tracking schedule, ghost schedule etc. Main pupose of internal schedule is to execute the works in the best possible ways incorporating all potential risk factors-both threats & oppurtunities. Also will be helpful to control the activities of sub-contractors using this internal schedule. Contractor will try to finish all the works ahead of schedule submitted to client, by closely monitoring the internal schedule with all best efforts.
BR
Kannan
Member for
16 years 3 monthsthis always becones a problem
this always becones a problem people ask what sechedule are you refering to. Not a good idea.